Insights
Publications

Data Centers Are “Critical Infrastructure,” and That May Help Mitigate Business Impacts From COVID-19

April 10, 2020 Articles

With millions of Americans staying at home during the COVID-19 crisis, news outlets and internet infrastructure companies are all reporting significant increases in internet usage.  For example, Cloudflare data from mid-March showed an 18% jump in internet traffic since the start of the year, and a study from Nielsen suggests that people staying home can lead to a 60% increase in consumption of streaming content.  And of course there’s the spike in the now-ubiquitous Zoom video conferencing service, which saw its peak number of users last year at 10 million per day explode to more than 200 million per day as of April 1. See Zoom’s “Message to Our Users.”

This dramatic increase in internet usage has put the spotlight on the unsung hero of today’s online economy: the data center.  Recognizing the central role they play in our economy, California’s government has designated data center employees as “critical infrastructure workers” not subject to mandatory shutdowns in three different economic sectors: utility data centers in the electricity industry, telecommunications data centers, and information technology data centers. See Gov. Gavin Newsom’s Exec. Order N-33-20 regarding Essential Critical Infrastructure Workers

Despite their designation as critical infrastructure, COVID-19 is already having significant impacts on the data center industry with many legal ramifications. 

For example, reports suggest that many data center construction projects are being put on hold for the safety of construction crews.  Construction delays may also be caused by supply chain slow-downs, particular for components sourced from China.  Who bears the risk for these construction delays is of course governed by the specific terms of the construction contract.  But many data center construction contracts use American Institute of Architecture forms, even if they’re modified through negotiation, and those contracts typically assign the risk to the project owner.  For example, the AIA A201-2017 General Conditions reads:

§ 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by … (3) unusual delay in deliveries,… or other causes beyond the Contractor’s control; … or (5) by other causes that the Contractor asserts, and the Architect determines, justify delay, then the Contract Time shall be extended for such reasonable time as the Architect may determine.

For further analysis of COVID-19’s impacts on construction projects, including risks that may be borne by subcontractors or suppliers, see the publication by our colleague Richard Shapiro, here.

There could also be increasing vacancies in co-location data center utilization where space is leased by third parties.  Those third parties might be wary of entering new contracts and unable to visit a data center site to ensure it complies with their needs, or they may be canceling contracts they already entered into.  Generally, parties canceling leases because of public health crises like COVID-19 might argue that the pandemic frustrates the purpose of the contract or, if shelter-in-place orders make it impossible to install equipment in a data center, they may argue that the lease contract fails for lack of consideration.  If the lease has a force majeure clause (many do not), that can also be a basis for attempting to void the contract.  See further analysis by our colleagues regarding force majeure here

The designation of data centers as essential infrastructure could provide ammunition to data center owners and operators to shift the risk for construction slow-downs and lease cancellations. 

Firm Highlights

Publication

A Roadmap to Litigating Privacy Claims? A Look at a Recent Order From the Google Assistant Privacy Litigation

As privacy-related litigation continues to heat up, Judge Beth Freeman (ND Cal.) recently laid out in In re Google Assistant Privacy Litigation (Case No. 19-cv-04286) [1] a potential roadmap for surviving or winning a...

Read More
News

Sushila Chanana Named to 2020 Leadership Council on Legal Diversity Fellows Program

SAN FRANCISCO, February 13, 2020: Farella Braun + Martel is proud to announce that Sushila Chanana has been named a member of the 2020 class of Fellows participating in a landmark program created by...

Read More
News

Farella Braun + Martel Announces 2020 Partner Elevations

SAN FRANCISCO/ST. HELENA, Calif., January 21, 2020: Northern California legal powerhouse Farella Braun + Martel is pleased to announce the election of senior associates Evan Abrams, Lauren Galbraith, and Alex Reese to the partnership...

Read More
Publication

Zoom Successfully Addresses New York’s Privacy and Security Concerns

A few weeks ago on this blog, we addressed some of the legal issues that have arisen for Zoom , as it becomes a significant part of American daily life during the COVID-19 pandemic. ...

Read More
News

Daily Journal Names Farella Lawyers Among Top IP Lawyers in California

Farella Braun + Martel is proud to announce that partners Jeffrey M. Fisher and James L. Day were named to the 2020 list of “Top Intellectual Property Lawyers” in California by the Daily Journal...

Read More
Publication

Tips for Efficiently Managing New Trade Secret Risks Created by Shelter-In-Place Restrictions and Remote Working

On April 14, 2020, California Governor Gavin Newsom outlined the six “critical indicators” the state will monitor during the next phase of its COVID-19 response as it considers when to modify its statewide shelter-in-place...

Read More
Publication

Federal “COVID-19 Consumer Data Protection Act” Proposed

A group of Republican senators has proposed a new privacy law to govern the collection and use of certain personal information thought to be both important and at risk during the current coronavirus crisis...

Read More
News

Gov't Drops IP Theft Charges Against Ex-Jawbone Workers

Law360 reported that the U.S. Attorney’s Office for the Northern District of California in San Jose moved to dismiss all trade-secret-theft charges against the remaining four defendants in what was originally a six-defendant case...

Read More
Publication

CARES Act Paycheck Protection Program Summary (Updated)

The Coronavirus Aid, Relief, and Economic Security Act (CARES Act) Paycheck Protection Program (PPP) aims to provide qualifying small businesses, nonprofit organizations, veterans organizations, tribal businesses, sole proprietors, and independent contractors forgivable loans of...

Read More
News

California Cases to Watch in 2020

Jessica Nall was quoted in the article "California Cases to Watch in 2020" in Law360 .  Jessica commented on two high-profile criminal cases against former technology executives pending in the Northern District of California...

Read More